Terms & Conditions
We don’t like small print, but we need a set of Terms & Conditions so that we are fully compliant with the necessary laws and licences in the UK.
1. (a) You require the work to be carried out more urgently than agreed.
2. (b) You change the specification.
3. (c) Your premises are in some way unsuitable for the equipment and this was not apparent during the course of the telephone/e-mail conversation or there are circumstances which we should have been made aware of.
4. (d) any other special circumstances that arise and we were not made aware of in writing when supplying our original quotation arose.
• This includes:
• Re-visits of the installer/technicians/engineer for reconfiguration of the system.
• Remote viewing, where the customer is responsible for the availability of a broadband internet service, a router that provides the ‘PORT-FORWARDING’ function and a public (static) IP address.
• The installation work is outside the working hours of 9.00am – 6.00pm Monday Friday, except statutory holidays. Requests made by the customer to install outside these working hours will incur additional charges.
• Engineers are asked to work outside standard practices of installations. Unless stated on the Works Schedule or we were made aware in writing when supplying our original quotation. Installs should be carried out in easily accessible areas without the need for additional labour work.
• This includes:
• Underground cabling
• Redecoration
• Building work
• Removal of floor boards, Carpet lifting/laying
• Erecting poles
• Steel trunking/capping
• Exceptionally high ceilings
• Drilling through walls thicker than 300mm
NOTE ~ Additional charges may be made if our engineers/technicians/installers are not provided with access to doors, shutters, windows, or any other areas where cables and equipment needs to be installed thereby incurring extra cable length.
5.1 The equipment installed belongs to 360 CCTV Limited until the work is complete and paid for in full by you. If you do not pay the balance of the installation charge immediately upon completion of the work by our service engineer, we have the right to remove the equipment from your premises without notice. By signing the contract with us, you irrevocably authorise us to enter your premises to remove the equipment if payment remains outstanding.
If you didn’t give the business any money but we provided services during the cooling-off period at your request, you’ll be expected to pay for these.
• Consumable items of all kinds failing. Consumables are items with a finite life such as lamps and batteries.
• Work carried out by police, fire or other authorities, or by any telecommunication agency or other party.
10. APPLICABLE LAW
This contract is governed by the laws of England and Wales, Scotland or Northern Ireland as the case may be and each party submits to the jurisdiction of the Courts thereof.
Between you (‘the customer’) and 360 CCTV Limited, here known as 360 CCTV Limited (‘us’).
1. PURPOSE
1.1 The installed system CCTV System is designed to reduce the risk of loss or damage to your premises so far as this can be done by the use of this type of equipment. However, we do not guarantee that the system cannot be removed, tampered with or made to stop working by you or any unauthorised person. Should this happen, 360 CCTV Limited are not responsible for any losses you may suffer directly or indirectly.
2. PAYMENT
2.1 A deposit of 25% of the agreed cost of work will be required when the order for installation is placed, this is to reserve a booking slot with our engineer.
2.2 The balance is payable immediately upon completion of the work by our service engineer.
2.3 Payment is by cash or bank transfer, full payment is to be completed BEFORE the engineer leaves the property. WE DO NOT ACCEPT CHEQUES.
2.4 We expect you to pay monies due promptly. If payment to us is overdue, we will charge you interest at 8.5% over the base rate of National Westminster Bank, from the date of our invoice until the date you pay PLUS a late payment fee of £99.00 Should you refuse to pay the money plus any interest and late payment fee due to us, we will transfer the payment collection to a debt recovery agent or solicitor. The additional costs of the debt collection and any legal and court fees will also apply.
3. COSTS
3.1 All quotes are valid for a period of 30 days.
3.2 The quoted costs may be revised if:
2. (b) You change the specification.
3. (c) Your premises are in some way unsuitable for the equipment and this was not apparent during the course of the telephone/e-mail conversation or there are circumstances which we should have been made aware of.
4. (d) any other special circumstances that arise and we were not made aware of in writing when supplying our original quotation arose.
• This includes:
• Re-visits of the installer/technicians/engineer for reconfiguration of the system.
• Remote viewing, where the customer is responsible for the availability of a broadband internet service, a router that provides the ‘PORT-FORWARDING’ function and a public (static) IP address.
• The installation work is outside the working hours of 9.00am – 6.00pm Monday Friday, except statutory holidays. Requests made by the customer to install outside these working hours will incur additional charges.
• Engineers are asked to work outside standard practices of installations. Unless stated on the Works Schedule or we were made aware in writing when supplying our original quotation. Installs should be carried out in easily accessible areas without the need for additional labour work.
• This includes:
• Underground cabling
• Redecoration
• Building work
• Removal of floor boards, Carpet lifting/laying
• Erecting poles
• Steel trunking/capping
• Exceptionally high ceilings
• Drilling through walls thicker than 300mm
• The above will incur additional charges as agreed by the company representatives if required.
4. GENERAL
4.1 Any prices quoted on this site are for installations within 10 miles of Wombourne, Wolverhampton. Prices are available on application for locations outside of this area.
4.2 The company (360 CCTV Limited) will endeavor to deliver and/or complete security systems as soon after receipt of an order as possible but cannot accept any responsibility or liability whatsoever for any claim arising in connection with any delay in delivery or completion howsoever caused.
4.3 You agree to give us and our workers full access to your premises to survey, measure, install, test and service the equipment. You also agree to provide an adequate electricity supply for the equipment to operate correctly. If our work is interrupted or delayed because of a problem with access, or the electricity supply is inadequate, we may make an additional charge. We are not liable if completion is delayed due to circumstances beyond our control. By signing the contract with us, you guarantee that you have full authority to allow the installation and no other consent is needed.
5. EQUIPMENT
5.2 If you want to cancel a service you’ve arranged online or over the phone you get a 14-day cooling-off period you also get this cooling-off period if you were approached by the business somewhere away from the business’s premises, during the 14 days you can cancel for any reason and get your money back.
If you paid up front or made a deposit and cancel in the cooling-off period you’ll be entitled to receive all of the money back. The only exception is if you asked for services to be provided during the cooling-off period, in which case the business will keep what’s necessary to cover the cost of services provided up until you cancelled.If you didn’t give the business any money but we provided services during the cooling-off period at your request, you’ll be expected to pay for these.
5.3 To ensure consistency of installation, quality and service our engineers may perform pre and post installation checks on the equipment and will photograph completed installations.
5.4 We will provide full training on completion of installation.
6. GUARANTEE / WARRANTY
We provide a warranty period of 36 months on all of our Hikvision CCTV products. The first 12 months also include labour where applicable during the RMA process.
6.1 The customer must notify us immediately of a fault occurring with the security system and we will repair such fault as soon as possible after receiving notification.
6.2 All CCTV equipment used by 360 CCTV Limited is of professional grade and comes with a three year guarantee. During the second and third years, the guarantee is via the manufacturer of the equipment so there will be a labour charge payable for services if anything goes wrong with the system.
6.3 The guarantee does not apply if we believe or have reason to suspect that changes have been made to a system/products supplied by our company or to faults caused by the following:
• Incorrect adjustment or positioning by you or others of any part of the system.• Consumable items of all kinds failing. Consumables are items with a finite life such as lamps and batteries.
• Work carried out by police, fire or other authorities, or by any telecommunication agency or other party.
7. REMOTE VIEWING & IT ISSUES
If we are unable to configure the remote viewing on the day of the scheduled installation due to IT technical issues, ISP unavailability or lack of details such as Router IP address, user name and password then further charges will apply to remotely configure or revisit to complete the set up.The company (360 CCTV Limited) cannot be held liable for client IT issues such as change of router, failed connection, change of internet service provider, re-set of router, new mobile phone, loss of settings on the router or a new operating system.
8. LIABILITY
8.1 The company (360 CCTV Limited) shall not be liable for the costs of any work, repairs or replacement of equipment which results from fire, electrical power surge, storm, flood, accident, neglect, misuse or malicious damage.
8.2 The company (360 CCTV Limited) does not warrant or represent that that the operation of the installation will be uninterrupted or error free. We provide the system to assist in the security of the customers premises but does not thereby warrant the security of the property, the customer or the contents therein.
8.3 The company (360 CCTV Limited) does not act and shall not be deemed to act as an insurer of the customers property or contents contained therein and give no warranty that by virtue of the installation of the system, the property or contents contained therein are completely secure or inviolable.
8.4 The company (360 CCTV Limited) shall have no liability in contract for any loss suffered and in particular, we do not accept any liability whatsoever for any consequential loss or damage (including loss of earnings or profits) which may arise from any malfunction or defect of the system.
8.5 The terms and conditions given in this contract do not affect your rights under the Sale of Goods Act or Unfair Contract Terms Act.
9. FORCE MAJEURE
360 CCTV Limited shall not be liable to the customer or deemed to be in breach of Contract by reason of any delay in performing, or any failure to perform, any obligations in relation to the equipment, provided that the delay or failure was due to any cause beyond reasonable control of 360 CCTV Limited. Without prejudice to the generality of the foregoing, the following shall be regarded as causes beyond reasonable control of 360 CCTV Limited : Act of God, explosion, flood, tempest, fire or accident; war or threat of war, sabotage, insurrection, civil disturbance or requisition; acts, restrictions, regulations bye-laws, prohibitions or measures of any kind on the part of any governmental, parliamentary or local authority; import or export regulations or embargoes; strikes, lock-outs or other industrial actions or trade disputes (whether involving employees of 360 CCTV Limited or of a third party); difficulties in obtaining raw materials, labour, fuel, parts or machinery; power failure or breakdown in machinery.
This contract is governed by the laws of England and Wales, Scotland or Northern Ireland as the case may be and each party submits to the jurisdiction of the Courts thereof.
